Laserfiche WebLink
General Conditions - 9 <br />C. This Contract contains the complete and integrated understanding and Contract between the <br />parties and supersedes any understanding, agreement, or negotiation, whether oral or written, <br />not set forth herein. <br /> <br />D. Unless otherwise directed in writing by the City’s Project Manager, notices to the City must be in <br />writing and shall be delivered to the City’s Project Manager by registered or certified mail, <br />postage prepaid, or delivered by hand. Notices to the Contractor may be delivered to the <br />Contractor by mail or email to the address for Contractor on Form 3.01 or to any other address <br />reasonably calculated to give the Contractor notice. <br /> <br />E. This Contract may only be modified by a written change order executed in accordance with the <br />Contract. <br /> <br />F. If any part of this Contract is found to be in conflict with applicable laws, such part shall be <br />inoperative, null, and void, insofar as it is in conflict with said laws, and the remainder of the <br />Contract shall remain in full force and effect. <br /> <br />G. Exclusive venue for any lawsuit arising out of this Contract shall be in the Superior Court of <br />Snohomish County, Washington. The laws of the State of Washington, without giving effect to <br />principles of conflict of laws, govern all matters arising out of or relating to this Contract. <br /> <br />H. The Contractor shall be in compliance at all times with all governmental laws, regulations, <br />requirements, and orders relating to COVID-19 applicable to the Project, including without <br />limitation OSHA, L&I, or other safety rules relating to COVID-19 and COVID-19 gubernatorial <br />proclamations and orders. These laws, regulations, requirements, and orders are referred to as <br />“COVID-19 Requirements.” The Contract Price includes all costs necessary for the duration of <br />the Project for compliance with COVID-19 Requirements. The Contract Price takes into account <br />that COVID-19 Requirements may create direct and indirect costs, including inefficiency and <br />delay. Contractor shall have no entitlement to an adjustment or other increase to the Contract <br />Price for any direct or indirect costs (including without limitation delay, cumulative impact, <br />inefficiency, or ripple costs) incurred by the Contractor to comply with COVID-19 Requirements.