9001 AIRPORT RD BLDG 1 2025-10-21

SNO-ISLE TECH 2O23 SMALL WORKS McGRANAHAN ARCHITECTS Section 00 70 00, Page 47 GENERAL CONDITIONS .5 Reasonable evidence that the Work will not be completed within the Contract Time, and that the unpaid balance would not be adequate to cover liquidated damages for the anticipated delay; .6 Failure to carry out the Work in accordance with the Contract Documents; .7 If Owner or Architect, in its good faith judgment, determines that the portion of the Contract Sum then remaining unpaid will not be sufficient to complete the Work in accordance with the Contract Documents, then the Owner shall make no additional payments and none will become due to the Contractor unless and until the Contractor, at its sole cost, performs a sufficient portion of the Work so that the Contract Sum then remaining unpaid is determined by the Owner or Architect to be sufficient to so complete the Work; .8 Failure of the Contractor to submit timely schedule updates as required by the Contract Documents; or delay by the Contractor and/or its Subcontractor(s) of any tier, or failure to comply with Contractor's Progress Schedule; or .9 Liquidated damages. 9.5.2 When the above reasons for withholding certification are removed, certification will be made for amounts previously withheld. 9.5.3 Owner shall not be deemed to be in breach of this Contract by reason of the withholding of any payment if the Work in question shall have been rejected by any governmental authority. The Owner shall have no obligation to make payments for defective Work and unsatisfactory performance until such Work and performance is corrected or replaced as provided herein and compensation is thereby earned. 9.5.4 Pursuant to RCW 39.12, the Contractor will not receive any payment until the Contractor and all Subcontractors of any tier have submitted a "Statement of Intent to Pay Prevailing Wage" to the Owner. The statement must have the approval of the Industrial Statistician of the Department of Labor and Industries before it is submitted to the Owner. The statement must include the Contractor's registration number, the number of workers in each trade classification, and the applicable wage rate for each trade listed. The Contractor agrees to provide each Subcontractor with a schedule of applicable prevailing wage rates. The Contractor and the respective Subcontractors shall pay all fees required by the Department of Labor and Industries, including fees for the approval of the "Statement of Intent to Pay Prevailing Wages." Approved copies of the "Statement of Intent to Pay Prevailing Wages" must be posted where workers can easily read them. 9.6 PROGRESS PAYMENTS 9.6.1 After the Architect has issued a Certificate for Payment, the Owner shall make payment in the manner and within the time provided in the Contract Documents, and shall so notify the Architect. The Owner will make a progress payment within thirty (30) days of its receipt of the Architect's Certificate for Payment, but shall be entitled to withhold payment according to subparagraph 9.5, notwithstanding the issuance of a Certificate for Payment. mcg-ARC 2120.000 February 28, 2023