Laserfiche WebLink
CITY OF EVERETT PUBLIC WORKS 00 61 25 <br /> SPECIAL PROVISIONS RETAINAGE ESCROW AGREEMENT <br /> ' DOCUMENT 00 61 25—RETAINAGE ESCROW AGREEMENT <br /> Project I Three Lakes Valve Bypass (UP3611) <br /> Contractor <br /> CITY OF <br /> Bank <br /> 1. Escrow Agreement. The Contractor on a public improvement project for the City exercised <br /> its option pursuant to RCW 60.28.011 (1994)to place Retainage in escrow with the Bank. This <br /> Agreement constitutes both the escrow agreement between the City and Contractor and <br /> instructions to the Bank for handling of the Escrow Account. This Agreement is not effective <br /> until (a)the Agreement has been signed by the Contractor, Bank and City and (b) Contractor, <br /> Bank and City have entered the appropriate information in Exhibit A. <br /> 2. Check Issuance,Endorsement, and Deposit. From time to time,the City will issue a Check <br /> payable to the Bank and Contractor jointly. Contractor expressly authorizes and grants the <br /> ' power to the Bank to endorse the check on its behalf,to negotiate the check, collect the funds <br /> represented by the Check, and to deposit the funds so collected into the Escrow Account. These <br /> powers shall be deemed to be powers coupled with an interest and shall be irrevocable during the <br /> term of this escrow. <br /> 3. Investment of Funds. Funds and cash balances in the Escrow Account may be invested in <br /> Eligible Securities at the direction of the Contractor. For purchase of Eligible Securities, the <br /> ' Bank may follow the last written direction it received from the Contractor,provided such <br /> direction provides for investment in Eligible Securities. The Bank shall not invest any funds, <br /> cash balances, or proceeds of sale of Eligible Securities in any securities, bonds or accounts that <br /> are not Eligible Securities. Eligible Securities purchased pursuant to this Agreement shall be <br /> held by the Bank as custodian as part of this escrow. Eligible Securities shall be held in the <br /> Bank's name. Interest on the purchased Eligible Securities, if any, shall be paid to Contractor <br /> when,as and if any accrued interest is received by the Bank. <br /> 4. Eligible Securities. The following securities are deemed Eligible Securities, and the Bank <br /> may invest funds and cash balances in such securities at the direction of Contractor without <br /> further approval of the City, provided that any maturity dates are no Iater than 25 calendar days <br /> ' after the Completion Date and provided they are held in a manner and form that allows Bank <br /> alone to liquidate the securities as provided for in the Agreement. <br /> A. Bills, certificates,notes or bonds of the United States; <br /> B. Other obligations of the United States or its agencies; <br /> C. Obligations of any corporation wholly owned by the Government of the United <br /> • <br /> D. States; <br /> Indebtedness of the Federal National Mortgage Association; <br /> E. Time deposits in commercial banks; and <br /> ' F. Mutual funds,pools, or investment trusts,provided the investments of the fund, <br /> pool or trust consists solely of securities listed in herein. <br /> Other securities may be deemed Eligible Securities upon written the written request of the <br /> ' Contractor and written approval of the City,provided the City has the staff assistance and <br /> expertise which will permit it to exercise sound judgment in assessing the security. The City <br /> ' THREE LAKES VALVE BYPASS July 19, 2017 <br /> WO#UP3611 00 61 25 - 1 <br />