Rodarte Construction 4/29/2019 - Laserfiche WebLink

CITY OF EVERETT SPECIAL PROVISIONS Shall: Required conduct. Shown: Refers to information presented on the Plans, with or without reference to the Plans. Specify: Refers to information described, shown, noted or presented in any manner in the Contract. I Submittals: The information required by the Contract Documents provided by Contractor to the City's Representative or City. Total Float: The amount of time a given activity or path of activities may be delayed before it will affect the Completion Date. Traffic: Both vehicular and non-vehicular traffic, such as pedestrians, bicyclists, wheelchairs, and equestrian traffic. I Unabsorbed Overhead: The reduction or loss of contribution to recovery of the Contractor's Overhead costs realized by the result of reduced Project or Contractor billings, or both, due to any reason whatsoever, including a Project extension. Unit Price Work: Refers to items of Work identified by unit prices in the Proposal. 1-02 BID PROCEDURES AND CONDITIONS 1-02.1 Pre qualifications of Bidders Delete 1-02.1 and substitute the following: 1-02.1 Bidder Responsibility Criteria (******) 1-02.1(1) Mandatory Bidder Responsibility Criteria (******) Bidder shall meet mandatory responsibility criteria in accordance with RCW 39.04.350(1). The City may require the Bidder to submit documentation demonstrating compliance with the criteria under this 1-02.1(1). The Bidder must: 1. Registration. Have a current certificate of registration as a contractor in compliance with chapter 18.27 RCW, which must have been in effect at the time of Bid submittal; and 2. UBI. Have a current Washington Unified Business Identifier (UBI) number; and 3. State Requirements. If applicable: a. Have Industrial Insurance (workers' compensation) coverage for the bidder's I employees working in Washington, as required in Title 51 RCW; b. Have a Washington Employment Security Department number, as required in Title 50 RCW; and ' c. Have a Washington Department of Revenue state excise tax registration number, as required in Title 82 RCW. 4. Disqualification. Not be disqualified from bidding on any public works contract I under RCW 39.06.010 or 39.12.065(3). 5. Certification of Wage Compliance. Within the three-year period immediately preceding the date of the bid solicitation, not have been determined by a final and binding citation and notice of assessment issued by the department of labor and industries or through a civil judgment entered by a court of limited or general jurisdiction to have willfully violated, as defined in RCW 49.48.082, any provision of chapter 49.46, 49.48, or 49.52 RCW. Alverson Stormwater Separation February, 2019 WO No—UP3660 Division 1 —GENERAL REQUIREMENTS SP—42