Laserfiche WebLink
Everett WA 98201 <br /> or email to: accountspayable@everettwa.gov <br /> 1.35 MISCELLANEOUS <br /> A. Any waiver by the City or the breach of any provision of this Contract by the Contractor will not <br /> operate or be construed as a waiver of any subsequent breach by the Contractor or prevent the <br /> City from enforcing any such provisions thereafter. <br /> B. This Contract may not be assigned by the Contractor without the written consent of the City, <br /> which consent may be withheld in the City's sole discretion. <br /> C. This Contract contains the complete and integrated understanding and Contract between the <br /> parties and supersedes any understanding, agreement, or negotiation,whether oral or written, <br /> not set forth herein. <br /> D. Unless otherwise directed in writing by the City's Project Manager, notices to the City must be in <br /> writing and shall be delivered to the City's Project Manager by registered or certified mail, <br /> postage prepaid, or delivered by hand. Notices to the Contractor may be delivered to the <br /> Contractor by mail or email to the address for Contractor on Form 3.01 or to any other address <br /> reasonably calculated to give the Contractor notice. <br /> E. This Contract may only be modified by a written change order executed in accordance with the <br /> Contract. <br /> F. If any part of this Contract is found to be in conflict with applicable laws,such part shall be <br /> inoperative, null,and void, insofar as it is in conflict with said laws, and the remainder of the <br /> Contract shall remain in full force and effect. <br /> G. Exclusive venue for any lawsuit arising out of this Contract shall be in the Superior Court of <br /> Snohomish County,Washington. The laws of the State of Washington,without giving effect to <br /> principles of conflict of laws,govern all matters arising out of or relating to this Contract. <br /> H. The Contractor shall be in compliance at all times with all governmental laws, regulations, <br /> requirements, and orders relating to COVID-19 applicable to the Project, including without <br /> limitation OSHA, L&I,or other safety rules relating to COVID-19 and COVID-19 gubernatorial <br /> proclamations and orders.These laws, regulations, requirements,and orders are referred to as <br /> "COVID-19 Requirements."The Contract Price includes all costs necessary for the duration of <br /> the Project for compliance with COVID-19 Requirements. The Contract Price takes into account <br /> that COVID-19 Requirements may create direct and indirect costs, including inefficiency and <br /> delay. Contractor shall have no entitlement to an adjustment or other increase to the Contract <br /> Price for any direct or indirect costs (including without limitation delay, cumulative impact, <br /> inefficiency, or ripple costs) incurred by the Contractor to comply with COVID-19 Requirements. <br /> General Conditions-9 <br />