A-1 Landscaping and Construction, Inc. 7/20/2016

I 1 available or that the right of entry has been received. If the Contractor is delayed due to 2 acts of omission on the part of the Contracting Agency in obtaining easements, rights of 3 entry or right of way, the Contractor will be entitled to an extension of time. The 4 Contractor agrees that such delay shall not be a breach of contract. 5 6 Each property owner shall be given 48 hours notice prior to entry by the Contractor. This 7 includes entry onto easements and private property where private improvements must 8 be adjusted. 9 10 The Contractor shall be responsible for providing, without expense or liability to the 11 Contracting Agency, any additional land and access thereto that the Contractor may I 12 desire for temporary construction facilities, storage of materials, or other Contractor 13 needs. However, before using any private property, whether adjoining the work or not, 14 the Contractor shall file with the Engineer a written permission of the private property 15 owner, and, upon vacating the premises, a written release from the property owner of 16 each property disturbed or otherwise interfered with by reasons of construction pursued 17 under this contract. The statement shall be signed by the private property owner, or 18 proper authority acting for the owner of the private property affected, stating that111 19 permission has been granted to use the property and all necessary permits have been 20 obtained or, in the case of a release, that the restoration of the property has been 21 satisfactorily accomplished. The statement shall include the parcel number, address, I 22 and date of signature. Written releases must be filed with the Engineer before the 23 Completion Date will be established. 24 25 1-07.28 Title VI Notice 26 The City of Everett hereby gives public notice that it is the City's policy to assure full 27 compliance with Title VI of the Civil Rights Act of 1964, the Civil rights Restoration Act of 28 1987, and related statutes and regulations in all programs and activities. Title VI requires 29 that no person shall, on the grounds of race, color, sex, or national origin be excluded 30 from participation in, be denied the benefits of, or be otherwise subjected to 31 discrimination under any Federal Aid Highway program or other activity for which the 32 City receives Federal financial assistance. 33 34 Any person who believes they have been aggrieved by an unlawful discriminatory 35 practice under Title VI has a right to file a formal complaint with the City of Everett. Any 36 such complaint must be in writing and filed with the City's Title VI Coordinator within one 37 hundred eighty (180) days following the date of the alleged discriminatory occurrence. 38 Title VI Discrimination Complaint Forms may be obtained from the Human Resources 39 office at no cost to the complainant by calling (425) 257-8767. 40 41 Notification specific to bidders: 42 43 All bidders are hereby notified that the City of Everett will affirmatively ensure that in any 44 contract entered into pursuant to this Invitation to Bid, minority business enterprises will 45 be afforded full opportunity to submit bids in response to this invitation and will not be 46 discriminated against on the grounds of race, color, sex, or national origin in 47 consideration for an award. 48 49 1-08 PROSECUTION AND PROGRESS 50 51 Add the following section: 1 52 1-08.0 Preliminary Matters 53 I RIVERFRONT DEVELOPMENT NORTH WETLAND COMPLEX 56