Laserfiche WebLink
4 , <br />extension of time, liquidnted damaqes will not be charged to the <br />Contractor. It is understood and aareed bv the Contractor and Sound <br />or portion thereof, within the Contract Time. Time extensions shall be <br />issued via a Chanqe Order. Contractor shall not be entitled to anv <br />additional comqensation or Equitable Adiustment for anv unavoidable <br />delay <br />SP-11.07 TIME LIMITATION AND VENUE <br />The General Provisions are modified as follows: <br />Add Section 11.07 Time Limitation and Venue, as follows: <br />Contractor mav not sue. cr�ss-ciaim or brina anv action of anv kind whatsoever aqainst <br />Sound Transit after the exc`ration of one hundred eiahtv (180) davs from Substantial <br />resolution process recoqnized in this Contract shall toll this deadline until thiRv (30) davs <br />after such administrative or dispute resolution process is concluded. Venue for anv leaal <br />proceedinq shall be exclusivelv in the Superior Court of Washinqton in and for Ki�n <br />Countv The parties understand and aqree that the Contractor's failure to brina suit <br />within the time period provided shall be a complete bar to anV such claims or causes of <br />action. <br />END OF SECTION 00300 <br />SPECIAL PROVISIONS <br />� <br />Capital Projecls Commuler Rail Special Provisions IFB No. RTAICP 21-06 <br />� Everelt Station Phase 2 Section 00300 Page 12 Addendum No. 4 <br />