BNBuilders Inc. 6/14/2023 - Laserfiche WebLink

1A MONTHLY PROGRESS SCHEDULE UPDATES A. The Contractor is required to prepare and submit monthly Progress Schedule updates and to participate in monthly schedule update meetings with the Architect and Owner as described below. 1. Timely submission of updates is of significant and crucial importance to the management of the Project. Lack of, or late receipt of, updates diminishes their value to the Architect and Owner. If a monthly Progress Schedule update is not submitted to and reviewed with the Architect and Owner prior to the Contractor submitting its monthly Application for Payment; the monthly Schedule of Values amount for Progress Schedule updates may, at the Architect's sole judgment and discretion, be reduced from the Specified General Conditions by a unilateral Change Order (see Section 01 29 76, "Progress Payments -GCCM"). B. The Contractor shall prepare monthly Progress Schedule updates to reflect work progress achieved since the previous update. Historical performance data and/or records shall not be changed without approval of the Architect and Owner. C. The Contractor shall, in a second and subsequent report, incorporate any logic and duration changes that represent its revised planning, provided all such changes are identified and submitted to the Architect and Owner for comment in the narrative report required herein this section. D. The Contractor shall use and maintain a fixed end date when generating the required reports and diagrams for the Architect and Owner as specified by this section. The fixed end date shall be the Substantial Completion date. The fixed end date will be adjusted in subsequent updates only to reflect approved time extensions incorporated by Change Order. E. The Project shall be rescheduled each reporting period with: 1. An updated data date. 2. Actual start/finish dates. 3. Percent complete. 4. Remaining durations (for each activity in the "status" or"current file). F. Show changes occurring since the previous schedule submission, such as: 1. Any major changes in scope. 2. Activities modified since previous submission including, but not limited to, logic changes. 3. Revised projections for progress and completion, as applicable. 4. Any other identifiable changes. G. The Contractor shall account for all rain days,for major events,and similar excusable non- compensable delays, during which little or no work is progressed and that are acknowledged by the Architect and Owner, in the period within which the events occur. The Contractor may account for such delays within the Progress Schedule update by City of Everett Municipal Building February 3,2023 Everett Municipal Building Public Works Tenant Spec Sect 0132 16 Improvements 01 32 16-6 Construction Progress Schedule RFFP for GC/CM Services